6/9/2020 E-Library - Information At Your Fingertips: Printer Friendly Filipino contractor.”[27] On 27 August 1987, the Central Bank authorized the remittance for its account of the amount of US$876,564 (equivalent to ID271, 808/610) to Al Ahli Bank representing full payment of the performance counter-guarantee for VPECI’s project in Iraq. [28] On 6 November 1987, Philguarantee informed VPECI that it would remit US$876,564 to Al Ahli Bank, and reiterated the joint and solidary obligation of the respondents to reimburse the petitioner for the advances made on its counter-guarantee.[29] The petitioner thus paid the amount of US$876,564 to Al Ahli Bank of Kuwait on 21 January 1988.[30] Then, on 6 May 1988, the petitioner paid to Al Ahli Bank of Kuwait US$59,129.83 representing interest and penalty charges demanded by the latter bank. [31] On 19 June 1991, the petitioner sent to the respondents separate letters demanding full payment of the amount of P47,872,373.98 plus accruing interest, penalty charges, and 10% attorney’s fees pursuant to their joint and solidary obligations under the deed of undertaking and surety bond.[32] When the respondents failed to pay, the petitioner filed on 9 July 1991 a civil case for collection of a sum of money against the respondents before the RTC of Makati City. After due trial, the trial court ruled against Philguarantee and held that the latter had no valid cause of action against the respondents. It opined that at the time the call was made on the guarantee which was executed for a specific period, the guarantee had already lapsed or expired. There was no valid renewal or extension of the guarantee for failure of the petitioner to secure respondents’ express consent thereto. The trial court also found that the joint venture contractor incurred no delay in the execution of the Project. Considering the Project owner’s violations of the contract which rendered impossible the joint venture contractor’s performance of its undertaking, no valid call on the guarantee could be made. Furthermore, the trial court held that no valid notice was first made by the Project owner SOB to the joint venture contractor before the call on the guarantee. Accordingly, it dismissed the complaint, as well as the counterclaims and cross-claim, and ordered the petitioner to pay attorney’s fees of P100,000 to respondents VPECI and Eusebio Spouses and P100,000 to 3-Plex and the Santos Spouses, plus costs. [33] In its 14 June 1999 Decision,[34] the Court of Appeals affirmed the trial court’s decision, ratiocinating as follows: First, appellant cannot deny the fact that it was fully aware of the status of project implementation as well as the problems besetting the contractors, between 1982 to 1985, having sent some of its people to Baghdad during that period. The successive renewals/extensions of the guarantees in fact, was prompted by delays, not solely attributable to the contractors, and such extension understandably allowed by the SOB (project owner) which had not anyway complied with its contractual commitment to tender 75% of elibrary.judiciary.gov.ph/thebookshelf/showdocsfriendly/1/45413 4/17